Friday 6 February 2015

Whether court can grant compensation for breach of contract even though no loss is proved?



Court observed that there is no dispute that the appellant failed to execute the work of construction of sewerage pumping station within the stipulated or extended time. The  pumping station was of public utility to maintain and preserve clean environment, absence of which could result in environmental degradation by stagnation of water in low lying areas. Delay also resulted in loss of interest on blocked capital. In these circumstances, loss could be assumed, even without proof and burden was on the appellant who committed breach to show that no loss was caused by delay or that the amount stipulated as damages for breach of contract was in the nature of penaltyEven if technically the time was not of essence, it could not be presumed that delay was of no consequence.
Court relied on Saw Pipes Case in which Sections 73 and 74 of the Indian Contract Act were discussed. It was observed that Section 74 emphasizes that in case of breach of contract, the party complaining of the breach is entitled to receive reasonable compensation whether or not actual loss is proved to have been caused by such breach. Therefore, the emphasis is on reasonable compensation. If the compensation named in the contract is by way of penalty, consideration would be different and the party is only entitled to reasonable compensation for the loss suffered. But if the compensation named in the contract for such breach is genuine pre-estimate of loss, which the parties knew when they made the contract to be likely to result from the breach of it, there is no question of proving such loss or such party is not required to lead evidence to prove actual loss suffered by him. Burden is on the other party to lead evidence for proving that no loss is likely to occur by such breach.

REPORTABLE
IN THE SUPREME COURT OF INDIA
CIVIL APPELLATE JURISDICTION
CIVIL APPEAL NOS...1440-1441 OF 2015
(ARISING OUT OF SLP (C) NOS.35365-35366 OF 2012)
M/S. CONSTRUCTION & DESIGN SERVICES
...APPELLANT
VERSUS
DELHI DEVELOPMENT AUTHORITY
Dated;FEBRUARY 4, 2015
ADARSH KUMAR GOEL, J.

1. Leave granted.
2. These appeals have been preferred against final judgment
and order dated 10th February, 2012 in RFA(OS) No.35 of 2010 and
dated 1st June, 2012 in R.P. No.369 of 2012 in RFA (OS) No.35 of
2010 passed by the High Court of Delhi at New Delhi.
3.
The question raised for our consideration is when and to what
extent can the stipulated liquidated damages for breach of a
contract be held to be in the nature of penalty in absence of
evidence of actual loss and to what extent the stipulation be taken
to be the measure of compensation for the loss suffered even in
absence of specific evidence. Further question is whether burden of
Page 1
2
proving that the amount stipulated as damages for breach of
contract was penalty is on the person committing breach.
4.
The respondent – Delhi Development Authority awarded a
contract vide agreement dated 4th October, 1995 to the appellant for
constructing a sewerage pumping station at CGHS area at Kondli
Gharoli at Delhi. Clause 2 in the agreement provided as follows:
“the contractor shall comply with the
said time schedule. In the event of the
contractor failing to comply with this
condition, he shall be liable to pay as
compensation an amount equal to one
percent or such smaller amount as the
Superintending
Engineer
Delhi
Development Authority (whose decision
shall be final) may decide on the said
estimated cost of the whole work for
everyday that the due quantity of work
remains incomplete;
provided always
that the entire amount of compensation
to be paid under the provisions of this
clause shall not exceed ten percent of
the estimated cost of work as shown in
the tender.”
Since the work proceeded at slow pace and the appellant-defendant
failed to complete the same, the contract was terminated on 17 th
September,
1999.
Under
Clause
2
of
the
agreement,
the
Superintending Engineer of the respondent levied compensation of
Rs.20,86,446/- for delay in execution of the project by an order of
penalty dated 21st July, 1999 and called upon the appellant to
deposit the same. The said order reads thus :
“The work was being executed by you at
extremely slow pace.
You had to
complete the job by 7.1.97. You had
failed to complete the work even after
Page 2
3
expiry of 2 years six months after
stipulated date of completion. Despite
the clear direction from Hon’ble Supreme
Court to expedite the work and complete
the job by June-99, you have failed to
comply the direction of Court and have
rather abandoned the work since 6.4.99
and you failed to complete the work till
date.
In exercise of the power conferred on me
under clause-2 of the agreement, I, R.C.
Kinger, the SE/CC-10/DDA decide and
determine that you are liable to pay
Rs.20,86,446/- (Rs. Twenty lacs eighty
six thousand four hundred forty six only)
as and by way of compensation as
stipulated in clause-2 of the agreement.”
5.
On failure of the appellant to respond to the above order, the
respondent filed suit No.1311 of 2002 before the Delhi High Court
for recovery of the said amount with interest.
The appellant-
defendant failed to contest the suit inspite of service but made an
application raising objection to the maintainability of the suit on the
ground that vide order dated 19 th December, 2001, a former Judge
of Delhi High Court had been appointed arbitrator to decide the
disputes arising out of the contract. The said application was,
however, dismissed on the ground that the matter in the suit was
not within the purview of the arbitration. The Court proceeded to
decide the suit on merits.
6.
Learned single Judge dismissed the suit holding that the
plaintiff had not treated the time fixed for performance of the
contract as of essence and the compensation stipulated in Clause 2
Page 3
4
of the agreement was in the nature of penalty. The basis for levy of
compensation had not been indicated so as to determine whether
the compensation claimed was reasonable. Reliance was placed on
the judgment of this Court in M/s. Arosan Enterprises Ltd. vs.
Union of India and another1 in support of the view that the time
stipulated in the agreement was not treated to be of essence. It was
further observed that since the claim for compensation was based on
sole discretion and not on the basis of loss suffered, the same was in
the nature of penalty and thus, the said Clause could not be enforced
in view of Section 74 of the Contract Act as laid down in Fateh
Chand vs. Bal Kishan Das2, Maula Bux vs. Union of India3, M.L.
Devendra Singh vs. Syed Khaja4, P D’Souza vs. Shondrilo
.
Naidu5 and Oil and Natural Gas Corporation Ltd. vs.
Saw
Pipes Ltd.6. Learned single Judge concluded as follows:-
“20.
The Court is of opinion that the
plaintiff having not treated the contract
as of the essence, and having extended
the time for performance on several
occasions, cannot now fall back on a
presumptive condition to impose the
maximum
compensation
leviable;
enforcement of such action would be
giving effect to a penalty clause. As far
as granting reasonable compensation is
concerned, the plaintiff has not shown
even
the
basis
for
levying
the
compensation that it did in this case. As
said earlier, this aspect assumes
1 (1999) 9 SCC 449
2 (1964) 1 SCR 515
3 (1969) 2 SCC 554
4 (1973) 2 SCC 515
5 (2004) 6 SCC 649
6 (2003) 5 SCC 705
Page 4
5
significance, because the plaintiff was
aware what extent of the contract was
performed, as well as what was the exact
extent of loss, in monetary terms, either
by way of payment to another contractor,
or the amount spent for completing the
work. In the circumstances, the Court is
of opinion that the relief sought cannot
be granted.”
7.
On appeal, the Division Bench reversed the view taken by the
learned single Judge.
It was held that delay in a contract of
construction of a public utility service could itself be a ground for
compensation without proving the actual loss. Accordingly, the suit
was decreed for payment of Rs.20,86,446/- with pendente lite and
future interest @ 9% per annum. It was observed:
“5.
The
respondent
had
been
proceeded against ex-parte at the trial
and has chosen not to appear even
before us.
The evidence led by the
appellant has remained unrebutted.
6.
Suffice would it be to state that the
observations of the Supreme Court in
para 68 of the decision reported as AIR
203 SC 2629 ONGC v. Saw Pipes Ltd. are
squarely applicable in the instant case as
per which delayed constructions such as
completing construction of road or
bridges within stipulated time would be
difficult to be linked with actual loses
suffered by the State and in such cases
the pre-estimated damages envisaged in
the contract have to be paid.
7.
Now, a Sewage Pumping Station is
not something from which Revenue
would be generated by the State. It is a
public utility service and has a role to
play in maintaining or preserving clean
environment. If Sewage Pumping Station
are not set up, sewage would stagnate
as cess pools in low lying areas and
Page 5
6
would cause environmental degradation,
both air and soil.
That apart, in a
delayed project, interest on blocked
capital would obviously be a measure of
damages.
8.
The learned Single Judge has
ignored as aforesaid and held that in the
absence
of
proof
of
damages,
compensation levied under clause-2
cannot be recovered. The learned Single
Judge is incorrect in view of the law
declared by the Supreme Court and thus
we allow the appeal and set aside the
impugned decree.
Suit filed by the
appellant is decreed in sum of
Rs.20,86,446/- with pendente lite and
future interest @ 9% per annum from
date of suit till realization and the suit
filed by the appellant is disposed of
accordingly with costs all throughout.”
8. The appellant filed a review petition which was dismissed.
9. We have heard learned counsel for the parties.
10. On 19th November, 2012 notice was issued subject to the
appellant depositing the entire decretal amount in this Court and by
a subsequent order, the amount was directed to be kept in term
deposit for a period of one year to ensure for the benefit of the
successful party.
Accordingly, the amount of Rs.20,86,500/- is said
to have been deposited which has been kept in FDR which is going
to mature on 8th February, 2015.
11.
Learned counsel for the appellant submitted that the Division
Bench erred in holding that the entire amount of stipulated damages
was genuine measure of compensation when instead of any fixed
amount, only the maximum amount of compensation was stipulated.
Page 6
7
The contract in question only envisaged the upper limit of damages
which could be claimed. It is submitted that the agreement quoted
in earlier part of the order clearly shows that what is stipulated is
that the compensation shall not exceed 10% of the estimated cost
and the amount to be recovered as compensation was required to be
determined by the Superintending Engineer.
The respondent-
plaintiff has failed to show the actual amount of loss suffered in
getting the work executed from any other contractor.
In these
circumstances, at best a part of it could be taken to be
compensation and the remaining penalty.
He submitted that the
judgment of this Court in Saw Pipes Ltd. (supra) relied upon by
the High Court is distinguishable in the fact situation of the present
case.
Without determining that the stipulated compensation was
reasonable, the maximum amount stipulated could not be treated as
compensation.
12.
Learned counsel for the respondent-plaintiff on the other hand
submitted
that
even
though
in
the
order
passed
by
the
Superintending Engineer no specific basis has been shown, notice
was duly issued to the appellant defendant before determining the
reasonable amount of compensation and claiming 10% of the project
cost which was stipulated to be the maximum compensation, on
account of delay in execution of the project.
On failure of the
appellant to respond, the entire amount has been rightly held to be
Page 7
8
the estimate of damages for the loss. Burden was on the defendant
to show that no loss or lesser loss was suffered by the plaintiff.
13. We have given due consideration to the rival submissions.
14. There is no dispute that the appellant failed to execute the work
of construction of sewerage pumping station within the stipulated or
extended time.
The said pumping station certainly was of public
utility to maintain and preserve clean environment, absence of which
could result in environmental degradation by stagnation of water in
low lying areas.
Delay also resulted in loss of interest on blocked
capital as rightly observed in para 7 of the impugned judgment of the
High Court.
In these circumstances, loss could be assumed, even
without proof and burden was on the appellant who committed
breach to show that no loss was caused by delay or that the amount
stipulated as damages for breach of contract was in the nature of
penalty. Even if technically the time was not of essence, it could not
be presumed that delay was of no consequence.
15.
Thus, even if there is no specific evidence of loss suffered by
the respondent-plaintiff, the observations in the order of the Division
Bench that the project being a public utility project, the delay
itself can be taken to have resulted in loss in the form of environmental
degradation and loss of interest on the capital are not without
any basis.
Page 8
9
16.
Once it is held that even in absence of specific evidence, the
respondent could be held to have suffered loss on account of breach of
contract, and it is entitled to compensation to the extent of loss
suffered, it is for the appellant to show that stipulated damages are by
way of penalty.
In a given case, when highest limit is stipulated
instead of a fixed sum, in absence of evidence of loss, part of it can be
held to be reasonable, compensation and the remaining by way of
penalty.
The party complaining of breach can certainly be allowed
reasonable compensation out of the said amount if not the entire
amount.
If the entire amount stipulated is genuine pre-estimate of
loss, the actual loss need not be proved. Burden to prove that no loss
was likely to be suffered is on party committing breach, as already
observed.
17.
It is not necessary to refer to all the judgments on the point in
view of categorical pronouncement of this Court in Saw Pipes
(supra), laying down as follows:-
“64. It is apparent from the aforesaid
reasoning recorded by the Arbitral
Tribunal that it failed to consider Sections
73 and 74 of the Indian Contract Act and
the ratio laid down in Fateh Chand case
wherein it is specifically held that
jurisdiction of the court to award
compensation in case of breach of
contract is unqualified except as to the
maximum stipulated; and compensation
has to be reasonable. Under Section 73,
when a contract has been broken, the
party who suffers by such breach is
entitled to receive compensation for any
loss caused to him which the parties
Page 9
10
knew when they made the contract to be
likely to result from the breach of it. This
section is to be read with Section 74,
which deals with penalty stipulated in
the contract, inter alia (relevant for the
present case) provides that when a
contract has been broken, if a sum is
named in the contract as the amount to
be paid in case of such breach, the party
complaining of breach is entitled,
whether or not actual loss is proved to
have been caused, thereby to receive
from the party who has broken the
contract reasonable compensation not
exceeding the amount so named. Section
74 emphasizes that in case of breach of
contract, the party complaining of the
breach is entitled to receive reasonable
compensation whether or not actual loss
is proved to have been caused by such
breach. Therefore, the emphasis is on
reasonable
compensation.
If
the
compensation named in the contract is
by way of penalty, consideration would
be different and the party is only entitled
to reasonable compensation for the loss
suffered. But if the compensation named
in the contract for such breach is
genuine pre-estimate of loss which the
parties knew when they made the
contract to be likely to result from the
breach of it, there is no question of
proving such loss or such party is not
required to lead evidence to prove actual
loss suffered by him. Burden is on the
other party to lead evidence for proving
that no loss is likely to occur by such
breach. Take for illustration: if the parties
have agreed to purchase cotton bales
and the same were only to be kept as a
stock-in-trade. Such bales are not
delivered on the due date and thereafter
the bales are delivered beyond the
stipulated time, hence there is breach of
the contract. The question which would
arise for consideration is — whether by
such breach the party has suffered any
loss. If the price of cotton bales
fluctuated during that time, loss or gain
could easily be proved. But if cotton
Page 10
11
bales
are
to
be
purchased
for
manufacturing yarn, consideration would
be different...........
67. Take for illustration construction of a
road or a bridge. If there is delay in
completing the construction of road or
bridge within the stipulated time, then it
would be difficult to prove how much loss
is suffered by the society/State. Similarly,
in the present case, delay took place in
deployment of rigs and on that basis
actual production of gas from platform B-
121 had to be changed. It is undoubtedly
true that the witness has stated that
redeployment plan was made keeping in
mind
several
constraints
including
shortage of casing pipes. The Arbitral
Tribunal,
therefore,
took
into
consideration the aforesaid statement
volunteered by the witness that shortage
of casing pipes was only one of the
several reasons and not the only reason
which led to change in deploym7ent of
plan or redeployment of rigs Trident II
platform B-121. In our view, in such a
contract, it would be difficult to prove
exact loss or damage which the parties
suffer because of the breach thereof. In
such a situation, if the parties have pre-
estimated
such
loss
after
clear
understanding, it would be totally
unjustified to arrive at the conclusion
that the party who has committed
breach of the contract is not liable to pay
compensation. It would be against the
specific provisions of Sections 73 and 74
of the Indian Contract Act. There was
nothing on record that compensation
contemplated by the parties was in any
way
unreasonable.
It
has
been
specifically mentioned that it was an
agreed genuine pre-estimate of damages
duly agreed by the parties. It was also
mentioned that the liquidated damages
are not by way of penalty. It was also
provided in the contract that such
damages are to be recovered by the
purchaser from the bills for payment of
the cost of material submitted by the
Page 11
12
contractor. No evidence is led by the
claimant to establish that the stipulated
condition was by way of penalty or the
compensation contemplated was, in any
way, unreasonable. There was no reason
for the Tribunal not to rely upon the clear
and unambiguous terms of agreement
stipulating
pre-estimate
damages
because of delay in supply of goods.
Further, while extending the time for
delivery of the goods, the respondent
was informed that it would be required to
pay stipulated damages.”
18.
Applying the above principle to the present case, it could
certainly be presumed that delay in executing the work resulted in
loss
for
which
compensation.
the
respondent
was
entitled
to
reasonable
Evidence of precise amount of loss may not be
possible but in absence of any evidence by the party committing
breach that no loss was suffered by the party complaining of breach,
the Court has to proceed on guess work as to the quantum of
compensation to be allowed in the given circumstances. Since the
respondent also could have led evidence to show the extent of
higher amount paid for the work got done or produce any other
specific material but it did not do so, we are of the view that it will
be fair to award half of the amount claimed as reasonable
compensation.
19.
Accordingly, this appeal is partly allowed and the decree
granted by the High Court is modified to the effect that the
respondent-plaintiff is entitled to half of the amount claimed with
rate of interest as awarded by the High Court. Out of the amount

deposited in this Court, the respondent will be entitled to withdraw
the said decretal amount and the appellant will be entitled to take
back the remaining .
20.
The appeals are disposed of accordingly.
...................................................J.
(T.S. THAKUR)
...................................................J.
(ADARSH KUMAR GOEL)
NEW DELHI
FEBRUARY 4, 2015


Print Page

No comments:

Post a Comment